Last Updated: 12 February 2026
By accessing and using the Pulqx website (pulqx.com) or engaging our renovation services, you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our website or services. These terms constitute a legally binding agreement between you and Pulqx.
Pulqx provides professional home renovation and interior fit-out services for residential properties in Metro Manila, including but not limited to:
Specific services, scope, timeline, and pricing are defined in individual project contracts following consultation and site assessment.
Initial consultations are provided to assess project requirements and property conditions. Following consultation, we provide written project proposals that include scope of work, material specifications, timeline estimates, and pricing structure. Project proposals are valid for 30 days from the date of issuance unless otherwise specified. Acceptance of a proposal constitutes agreement to proceed with the project under the terms outlined.
Project pricing is determined based on scope, materials, labor requirements, and site conditions as assessed during consultation. All prices are quoted in Philippine Pesos (PHP) unless otherwise specified. Payment follows a milestone-based structure tied to completed work phases as outlined in the project contract. Payment is due within the timeframe specified for each milestone. Late payments may result in project delays. We reserve the right to suspend work if payment obligations are not met according to the agreed schedule.
Project timelines are estimates based on normal working conditions and material availability. Actual completion dates may vary due to factors including weather conditions, unforeseen site issues, material delivery delays, changes requested by the client, or circumstances beyond our reasonable control. We will communicate any anticipated delays promptly and work to minimize their impact on the overall project schedule.
Any changes to the approved project scope, materials, or specifications must be documented through written change orders. Change orders will detail the modifications, associated costs, and impact on project timeline. Additional work beyond the original scope will be billed separately according to the rates established in the project contract. We reserve the right to decline change requests that would compromise project quality or feasibility.
Clients are responsible for:
Pulqx will handle building permit applications and compliance documentation as required for the scope of work. Clients are responsible for providing any necessary property documentation or homeowner association approvals. All work is performed in accordance with applicable building codes and regulations. Additional costs for permit fees or compliance requirements will be outlined in the project proposal.
We warrant that work will be performed in a workmanlike manner using appropriate materials and construction methods. Specific warranty terms for materials and workmanship are provided in the project contract. Warranty coverage does not include damage resulting from normal wear and tear, misuse, lack of maintenance, modifications by others, or circumstances beyond our control. Warranty claims must be reported promptly to allow for timely resolution.
To the maximum extent permitted by law, Pulqx's liability for any claims arising from renovation services is limited to the total amount paid for the specific project giving rise to the claim. We are not liable for indirect, consequential, incidental, or punitive damages. This limitation applies regardless of the legal theory under which liability is asserted. Some jurisdictions do not allow limitation of certain damages, so these limitations may not apply in all cases.
Pulqx maintains appropriate insurance coverage for renovation work. Clients are responsible for maintaining their own property insurance and should notify their insurance provider of renovation work being performed. We are not responsible for damage to property or belongings outside the defined work area unless caused by our negligence.
Design concepts, drawings, and 3D visualizations created by Pulqx remain our intellectual property. Clients receive a license to use these materials for the specific renovation project. Materials may not be reproduced or used for other projects without our written permission. All website content, including text, images, and design elements, is protected by copyright and may not be reproduced without authorization.
Either party may terminate a project contract under the conditions specified in the agreement. Termination does not relieve the client of payment obligations for work completed and materials purchased up to the termination date. Upon termination, we will provide an accounting of completed work and associated costs. Any deposits or advance payments will be applied to completed work and non-returnable materials.
Any disputes arising from these Terms of Service or renovation projects will first be addressed through good faith negotiation between the parties. If negotiation does not resolve the dispute, parties agree to attempt mediation before pursuing legal action. Disputes that cannot be resolved through mediation will be subject to the jurisdiction of Philippine courts.
The Pulqx website is provided for informational purposes. While we strive to maintain accurate and current information, we make no warranties about the completeness or accuracy of website content. Information about services, pricing, and timelines on the website is general in nature; specific details are provided in individual project proposals following consultation.
Our collection and use of personal information is governed by our Privacy Policy, which is incorporated into these Terms of Service by reference. By using our services, you consent to our data practices as described in the Privacy Policy.
Pulqx reserves the right to modify these Terms of Service at any time. Updated terms will be posted on this page with a revised "Last Updated" date. Continued use of our website or services after changes constitutes acceptance of the modified terms. Material changes affecting existing project contracts will be communicated directly to affected clients.
If any provision of these Terms of Service is found to be invalid or unenforceable, the remaining provisions will continue in full force and effect. Invalid provisions will be modified to the minimum extent necessary to make them valid and enforceable while preserving their intent.
These Terms of Service are governed by the laws of the Republic of the Philippines. Any legal action or proceeding related to these terms or our services will be brought exclusively in the courts of the Philippines.
For questions about these Terms of Service or our renovation services, please contact:
Pulqx
2nd Floor, R&M Bldg., Zone 2
Cagayan De Oro City, Misamis Oriental
Phone: +63 888 817 063
Email: info@pulqx.com